Fidic合同(英文)通用条款(EPC)

1、General ConditionsGeneral Provisions1.1 Definitions In the Conditions of Contract (these Conditions), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meanings stated. Words indicating persons or parties include corporations and other legal entities, except where the context requires otherwise.1.1.1 The Contract1.1.1.1 Contract means the Contract Agreement, these Conditions, the Employers Requirements, the Tender, and the furthe

2、r documents (if any) which are listed in the Contract Agreement.1.1.1.2 Contract Agreement means the contract agreement referred to in Sub-Clause 1.6 Contract Agreement, including any annexed memoranda.1.1.1.3 Employers Requirements means the document entitled employers requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the W

3、orks.1.1.1.4 Tender means the Contractors signed offer for the Works and all other documents which the Contractor submitted therewith (other than these Conditions and the Employers Requirements, if so submitted), as included in the Contract1.1.1.5 Performance Guarantees and Schedule of Payments mean the documents so named (if any), as included in the Contract.1.1.2 Parties and Persons1.1.2.1 Party means the Employer or the Contractor, as the context requires.1.1.2.2 Employer means the person nam

4、ed as employer in the Contract Agreement and the legal successors in title to this person.1.1.2.3 Contractor means the person(s) named as contractor in the Contract Agreement and the legal successors in title to this person(s).1.1.2.4 Employers Representative means the person named by the Employer in the Contract or appointed from time to time by the Employer under Sub-Clause 3.1 The Employers Representative, who acts on behalf of the Employer.1.1.2.5 Contractors Representative means the person

5、named by the Contractor in the Contract or appointed from time to time by the Contractor under Sub-Clause 4.3 Contractors Representative, who acts on behalf of the Contractor.1.1.2.6 Employers Personnel means the Employers Representative, the assistants referred to in Sub-Clause 3.2 Other Employers Personnel and all other staff, labour and other employees of the Employer and of the Employers Representative; and any other personnel notified to the Contractor, by the Employer or the Employers Repr

6、esentative, as Employers Personnel.1.1.2.7 Contractors Personnel means the Contractors Representative and all personnel whom the Contractor utilises on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor; and any other personnel assisting the Contractor in the execution of the Works.1.1.2.8 Subcontractor means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal

7、successors in title to each of these persons.1.1.2.9 DAB means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 Appointment of the Dispute Adjudication Board or Sub-Clause 20.3 Failure to Agree Dispute Adjudication Board.1.1.2.10 FIDIC means the Federation Internationale des Ingenieurs-Conseils the international federation of consulting engineers.1.1.3 Dates, Tests, Periods and Completion1.1.3.1 Base Date means the date 28 days prior to the

8、 latest date for submission of the Tender.1.1.3.2 Commencement Date means the Commencement of Works, unless Agreement. date notified under Sub-Clause 8.1otherwise defined in the Contract1.1.3.3 Time for Completion means the time for completing the Works or aSection (as the case may be) under Sub-Clause 8.2 Time for Completion, as stated in the Particular Conditions (with any extension under Sub-Clause 8.4 Extension of Time for Completion), calculated from the Commencement Date.1.1.3.4 Tests on C

9、ompletion means the tests which are specified in Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 Tests on Completion before the Works or a Section (as the case may be) are taken over by the Employer1.1.3.5 “Taking-Over Certificate means a certificate issued under Clause 10 Employers Taking Over1.1.3.6 Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out under Clause 12 Tests after Completion after the Works or a Section (as the case may be) are taken by the Employer1.1.3.7 Defects Notification Period means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 Completion of Outstanding Work and Remedying Defects, as stated in the Particular Conditio

《Fidic合同(英文)通用条款(EPC)》由会员re****.1分享，可在线阅读，更多相关《Fidic合同(英文)通用条款(EPC)》请在金锄头文库上搜索。